PUBLIC NOTICES
Published In The Daily Transcript
Advertised public notices, printed in a newspaper of general circulation, are required by California law. Within the individual category, notices are arranged by print publish day in reverse chronological order.
Online, on a selected date, the notices are arranged in alphabetical order.

County of San Diego
PUBLISHED: Tuesday August 19, 2014

COUNTY OF SAN DIEGO
DEPARTMENT OF PURCHASING AND CONTRACTING
5560 OVERLAND AVE, STE 270
SAN DIEGO CA 92123
---
NOTICE TO CONTRACTORS

The County of San Diego, invites sealed bids for
INTERCOM MAINTENANCE SERVICES; RFB No. 6540

Sealed bids will be received at the Office of Purchasing and Contracting, 5560 Overland Avenue, Suite 270, San Diego, California, 92123-1204, until 11:00 a.m. on September 30, 2014 at which time they will be publicly opened and read aloud. RFB documents are available for download at the County BuyNet site: https://buynet.sdcounty.ca.gov . You must be registered at the site in order to download documents. The Contractor shall possess, at the time of submitting the bid, a California contractor's license, Classification C-7, Low Voltage Systems. The estimated value of the contract is $120,000 to $150,000 per year for an initial term of up to one (1) year and four (4) one-year options through November 2019. A mandatory pre-bid conference is scheduled at the office of Purchasing and Contracting on Wednesday, September 3, 2014 at 10:00 a.m. Information regarding mandatory job walks will be provided at the pre-bid conference. Bid security of no less than 10% required at time of bid for total price of the contract. Successful bidder shall provide Payment and Performance Bonds for 100% of and at each contract year. Prevailing Wage rates apply. The County, as a matter of policy, encourages the participation of Disabled Veterans Business Enterprise (DVBE). For complete bid information, go to County of San Diego Purchasing and Contracting website at https://buynet.sdcounty.ca.gov. For questions, please contact PCO, Jose Sandoval at jose.sandoval@sdcounty.ca.gov.
Pub. August 18 through August 29-00123141

COUNTY OF SAN DIEGO
DEPARTMENT OF PURCHASING AND CONTRACTING
5560 OVERLAND AVE, STE 270
SAN DIEGO, CA 92123
---
NOTICE TO CONTRACTORS


The County of San Diego, Owner, invites bids for CONSTRUCTION OF TJ SOUTHWEST TRAILS ENHANCEMENT: ORACLE PROJECT NO. 1018372; BID No. 6577.

Sealed bids will be received at the Department of Purchasing and Contracting, at 5560 Overland Avenue, Ste. 270, San Diego, 92123, until 2:00 PM on August 28, 2014, at which time they will be publicly opened and read aloud. Contract documents including Plans, Specifications and Bid Forms are available for download on the County Buynet site: https://buynet.sdcounty.ca.gov.You must be registered at the site in order to download documents. A pre-bid meeting is scheduled for 1:00 p.m. on Friday, August 22, 2014 at 2721 Monument Road, San Diego, CA within the Tijuana County Park Ranger Station. The Contractor shall possess, at the time of submitting the bid, a California contractor's license, Classification A, General Engineering Contractor. The cost of construction is estimated to be from $800,000 to $1,300,000. Bid security of no less than 10% required at time of bid. Successful bidder shall provide Payment and Performance Bonds for 100% of the contract amount. Prevailing Wage rates apply. The Owner, as a matter of policy, encourages Disabled Veterans Business Enterprise (DVBE) participation for this project. For complete bid information, go to County of San Diego Purchasing and Contracting website at http://buynet.sdcounty.ca.gov. For questions, please contact PCO, Kristen Hill at kristen.hill@sdcounty.ca.gov.
Pub. Aug 12 through Aug 25-00123009

COUNTY OF SAN DIEGO
DEPARTMENT OF PURCHASING AND CONTRACTING
5560 OVERLAND AVE STE 270
SAN DIEGO, CA 92123
---
NOTICE TO CONTRACTORS


The County of San Diego, Owner, invites bids for CONSTRUCTION OF TIJUANA RIVER VALLEY REGIONAL PARK MESA TRAILS ENHANCEMENT PROJECT: ORACLE PROJECT NO. 1018373; BID No. 6584.

Sealed bids will be received at the Department of Purchasing and Contracting, at 5560 Overland Avenue, Ste. 270, San Diego, 92123, until 2:00 PM on September 2, 2014, at which time they will be publicly opened and read aloud. Contract documents including Plans, Specifications and Bid Forms are available for download on the County Buynet site: https://buynet.sdcounty.ca.gov.You must be registered at the site in order to download documents. A pre-bid meeting is scheduled for 1:00 p.m. on Friday, August 28, 2014 at 2721 Monument Road, San Diego, CA within the Tijuana County Park Ranger Station. The Contractor shall possess, at the time of submitting the bid, a California contractor's license, Classification B, General Building Contractor. The cost of construction is estimated to be from $400,000 to $700,000. Bid security of no less than 10% required at time of bid. Successful bidder shall provide Payment and Performance Bonds for 100% of the contract amount. Prevailing Wage rates apply. The Owner, as a matter of policy, encourages Disabled Veterans Business Enterprise (DVBE) participation for this project. For complete bid information, go to County of San Diego Purchasing and Contracting website at http://buynet.sdcounty.ca.gov. For questions, please contact PCO, Kristen Hill at kristen.hill@sdcounty.ca.gov.
Pub. Aug 12 through Aug 25-00123011

SUPERIOR COURT OF THE
STATE OF CALIFORNIA
FOR COUNTY OF SAN DIEGO
NORTHERN DIVISION
No. CD253359
DA ADP204
NOTICE RE: PETITION FOR
PROTECTIVE ORDER PURSUANT TO PENAL CODE SECTION 186.11(e)
---

THE PEOPLE OF THE STATE OF
CALIFORNIA,
Petitioner,
v.
ROBERT O. YOUNG,
Defendant(s).
ON AUGUST 15, 2014, the San Diego District Attorney's Office instituted proceedings to preserve property to pay restitution as provided in Penal Code section 186.11. The approximate value of the property is $3,900,000. The property is further described as follows: Real Property located at 16390 Dia Del Sol, Valley Center, California, 92082, Assessor's Parcel No. 188-100-36-00.
If you have a legal interest in this property, you must within thirty (30) days of your receipt of this notice, file a verified claim stating the nature and extent of your interest with the Clerk of the Superior Court, 325 South Melrose Drive, Vista, California, 92081. An endorsed copy of the verified claim must be served upon the District Attorney, Suite 750, 330 West Broadway, San Diego, California, 92101
.
The Number indicated above has been assigned to this case; refer to this number in any communication with the Court or the District Attorney.
If no verified claim is properly filed, the District Attorney will seek to have the Court issue an order that the property be levied upon to pay fines and restitution.
Dated: August 15, 2014
BONNIE M. DUMANIS
District Attorney
By:_____________________________
GINA DARVAS
Deputy District Attorney, SBN 163221
Attorneys for Petitioner
330 West Broadway
San Diego, CA 92101
Tel.: (619) 531-4459
Fax: (619) 531-4481
Email: gina.darvas@sdcda.org
Pub Aug 19, 26, Sept 2 -00123171

SAN DIEGO COUNTY REGIONAL AIRPORT AUTHORITY
P. O. BOX 82776, SAN DIEGO, CA 92138-2776
WWW.SAN.ORG

NOTICE INVITING BIDS
---

Notice is hereby given that the Facilities Development Department of the San Diego County Regional Airport Authority (the "Authority") will receive sealed bids at San Diego County Regional Airport Authority Commuter Terminal 3rd Floor Reception Desk, located at 3225 North Harbor Drive, San Diego, California, until 2:00 P.M. on September 18, 2014, for:

Project No. 380802 Quieter Home Program Phase 8 Group 2
SAN DIEGO INTERNATIONAL AIRPORT
SAN DIEGO, CALIFORNIA


The magnitude of this work is in the range of $1,368,822.00. The bidder shall possess a valid California State Contractors License, classification B and shall also be certified by the Environmental Protection Agency as a Renovation Firm as defined by 40 CFR 745, Subpart E § 745.89 - Firm Certification at the time the Bid is submitted.

In addition, the contract work includes removal and disposal of asbestos-containing building materials. Bidder is not permitted to perform any asbestos-related work unless bidder possesses a California State Contractor's License and is certified pursuant to Section 7058.6 of the California State Business and Professions Code. If a certified subcontractor is used, the subcontractor's license and certification number shall be submitted by the bidder within the Bid Submission Documents.

The project includes sound attenuation improvements for certain residences around San Diego International Airport. The project includes 34 dwelling units located on 11 residential properties. Sound attenuation improvements may include, but are not limited to, replacement of windows and exterior doors, finely detailed, field-executed finish carpentry, added insulation and improvements to add air conditioning, ventilation, and electrical systems. The work will include the demolition and modification of existing construction to install new windows and doors and, in some cases, may require temporary weatherproof closures.

This project includes special treatment for "Potentially Historically" significant units. Contractors wishing to bid this Project must demonstrate a minimum of three (3) years successful experience in residential sound attenuating projects, specifically working on "Potentially Historic" homes, or a minimum of five (5) years successful experience in residential historic renovation projects of equal scope.

A mandatory pre-bid conference shall begin promptly at 2:00 p.m. on September 4, 2014 in the Conference Room at the Quieter Home Program office, Liberty Station Complex, 2722 Truxtun Road, San Diego, CA 92106. At the end of the conference, there will be a mandatory job site visit to tour a small number of homes that are representational of the overall scope of the anticipated work. Only potential Bidders who have signed all sign-in sheet(s), and attended the mandatory pre-bid meeting and job site visit, will be allowed to submit a bid for this project.

All questions relating to the information contained in the Request for Bid shall be set forth in writing and shall be directed to the Procurement Department Representative via email. Questions will be received until, 2:00 P.M. on September 12, 2014. Any questions received after that time and date will not be considered. The Procurement Department Representative is: Jeffrey Platt, Email: jplatt@san.org.

Bids will be opened in public immediately following the time for receipt referenced above, in the Commuter Terminal Boardroom, at 3225 North Harbor Drive, Commuter Terminal, third floor, San Diego, California. No Bidder may withdraw a bid after the time and date set for bid opening.

The solicitation may be downloaded at:
http://www.san.org, select Business Opportunities, select Open Solicitations; OR http://vendors.planetbids.com/SDCRAA/VendorLogin/VendorLogin.cfm

In order to download the solicitation, the Bidder must first register. Please follow this link below:
http://vendors.planetbids.com/SDCRAA/Vendor_Registration.cfm

If there are any issues with downloading these documents, please contact PlanetBids customer support at (818) 992-1771 or support@planetbids.com.In accordance with the provisions of the California State Labor Code, the Airport Authority has obtained the general prevailing rate of wages (which rate includes employer payments for health and welfare, vacation, pension and similar purposes) applicable to the work to be done, for straight time, overtime, Saturday, Sunday and holiday work. All labor employed on this project shall be paid no less than such minimum rates of wages.

It is the practice of the Airport Authority that certified Disadvantaged Business Enterprises (DBEs) shall have the maximum opportunity to participate in the performance of Airport Authority contracts. Certified DBEs with qualifying experience are encouraged to respond to the request for proposals/bids/quotes, etc.
Pub. Aug 19-00123162


County of San Diego
PUBLISHED: Tuesday August 19, 2014


Browse By Publication Date Months in 2014 Days in August 2014
2014 Public Notices
August
08/19/2014